Based on section
324 of title
40, U.S.C., 1940 ed., Public Buildings, Property and Works (June 19, 1912, ch. 174, § 1,37 Stat. 137).
This section contains only the jurisdictional provision in the last clause of section
324 of title
40, U.S.C., 1940 ed.
Changes in phraseology were made.
2006—Pub. L. 109–284substituted “chapter 37 of title
40” for “Contract Work Hours and Safety Standards Act” in section catchline.
2002—Pub. L. 107–217substituted “section
3703 of title
40” for “section 104 of the Contract Work Hours and Safety Standards Act”.
1992—Pub. L. 102–572substituted “United States Court of Federal Claims” for “United States Claims Court”.
1990—Pub. L. 101–650substituted “Hours and Safety Standards” for “Hours Standards” in text.
1982—Pub. L. 97–164substituted “Contract Work Hours and Safety Standards Act” for “Contract Work Hours Standards Act” in section catchline and “United States Claims Court” for “Court of Claims” in text.
1962—Pub. L. 87–581amended section generally, substituting “Liquidated damages withheld from contractors under Contract Work Hours Standards Act” for “Penalties imposed against contractors under eight hour law” in section catchline, and “liquidated damages withheld from a contractor or subcontractor under section 104 of the Contract Work Hours Standards Act” for “a penalty withheld from a contractor or subcontractor under section
324 of Title
40” in text.
Amendment by Pub. L. 87–581effective 60 days after Aug. 13, 1962, but shall not affect contracts existing or thereafter entered into pursuant to invitations for bids outstanding on Aug. 13, 1962, see section 204 ofPub. L. 87–581, Aug. 13, 1962, 76 Stat. 360.
Continued Jurisdiction Upon Claims Under Section 324 of Former Title 40
Pub. L. 87–581, title II, § 202(b),Aug. 13, 1962, 76 Stat. 360, provided that the Court of Claims (now United States Court of Federal Claims) was to continue to have jurisdiction to render judgment upon certain claims for a penalty withheld from a contractor or subcontractor under section 324 of former Title 40, Public Buildings, Property, and Works, in connection with any contract subject to that section existing on the date sixty days after Aug. 13, 1962, or thereafter entered into pursuant to invitations for bids that were outstanding on Aug. 13, 1962.
The table below lists the classification updates, since Jan. 3, 2012, for this section. Updates to a broader range of sections may be found at the update page for containing chapter, title, etc.
The most recent Classification Table update that we have noticed was Wednesday, February 6, 2013
An empty table indicates that we see no relevant changes listed in the classification tables. If you suspect that our system may be missing something, please double-check with the Office of the Law Revision Counsel.
Description of Change
Statutes at Large
LII has no control over and does not endorse any external Internet site that contains links to or references LII.