48 CFR Subpart 49.1 - General Principles

  1. 49.100 Scope of subpart.
  2. 49.101 Authorities and responsibilities.
  3. 49.102 Notice of termination.
  4. 49.103 Methods of settlement.
  5. 49.104 Duties of prime contractor after receipt of notice of termination.
  6. 49.105 Duties of termination contracting officer after issuance of notice of termination.
  7. 49.105-1 Termination status reports.
  8. 49.105-2 Release of excess funds.
  9. 49.105-3 Termination case file.
  10. 49.105-4 Cleanup of construction site.
  11. 49.106 Fraud or other criminal conduct.
  12. 49.107 Audit of prime contract settlement proposals and subcontract settlements.
  13. 49.108 Settlement of subcontract settlement proposals.
  14. 49.108-1 Subcontractor's rights.
  15. 49.108-2 Prime contractor's rights and obligations.
  16. 49.108-3 Settlement procedure.
  17. 49.108-4 Authorization for subcontract settlements without approval or ratification.
  18. 49.108-5 Recognition of judgments and arbitration awards.
  19. 49.108-6 Delay in settling subcontractor settlement proposals.
  20. 49.108-7 Government assistance in settling subcontracts.
  21. 49.108-8 Assignment of rights under subcontracts.
  22. 49.109 Settlement agreements.
  23. 49.109-1 General.
  24. 49.109-2 Reservations.
  25. 49.109-3 Government property.
  26. 49.109-4 No-cost settlement.
  27. 49.109-5 Partial settlements.
  28. 49.109-6 Joint settlement of two or more settlement proposals.
  29. 49.109-7 Settlement by determination.
  30. 49.110 Settlement negotiation memorandum.
  31. 49.111 Review of proposed settlements.
  32. 49.112 Payment.
  33. 49.112-1 Partial payments.
  34. 49.112-2 Final payment.
  35. 49.113 Cost principles.
  36. 49.114 Unsettled contract changes.
  37. 49.115 Settlement of terminated incentive contracts.