22.406-9Withholding from or suspension of contract payments.
(a)Withholding from contract payments. If the contracting officer believes a violation exists (see 22.406-8), or upon request of the Department of Labor, the contracting officer must withhold from payments due the contractor an amount equal to the estimated wage underpayment and estimated liquidated damages due the United States under the Contract Work Hours and Safety Standards Act. (See 22.302.)
(1) If the contracting officer believes a violation exists or upon request of the Department of Labor, the contracting officer must withhold funds from any current Federal contract or Federally assisted contract with the same prime contractor that is subject to either Davis-Bacon Act or Contract Work Hours and Safety Standards Act requirements.
(2) If a subsequent investigation confirms violations, the contracting officer must adjust the withholding as necessary. However, if the Department of Labor requested the withholding, the contracting officer must not reduce or release the withholding without written approval of the Department of Labor.
(3) Use withheld funds as provided in paragraph (c) of this subsection to satisfy assessed liquidated damages, and unless the contractor makes restitution, validated wage underpayments.
(b)Suspension of contract payments. If a contractor or subcontractor fails or refuses to comply with the labor standards clauses of the Davis-Bacon Act and related statutes, the agency, upon its own action or upon the written request of the Department of Labor, must suspend any further payment, advance, or guarantee of funds until the violations cease or until the agency has withheld sufficient funds to compensate employees for back wages, and to cover any liquidated damages due.
(c)Disposition of contract payments withheld or suspended—(1) Forwarding wage underpayments to the Comptroller General. Upon final administrative determination, if the contractor or subcontractor has not made restitution, the contracting officer must forward to the appropriate disbursing office Standard Form (SF) 1093, Schedule of Withholdings Under the Davis-Bacon Act (40 U.S.C. 276(a)) and/or Contract Work Hours and Safety Standards Act (40 U.S.C. 327-333). Attach to the SF 1093 a list of the name, social security number, and last known address of each affected employee; the amount due each employee; employee claims if feasible; and a brief rationale for restitution. Also, the contracting officer must indicate if restitution was not made because the employee could not be located. The Government may assist underpaid employees in preparation of their claims. The disbursing office must submit the SF 1093 with attached additional data and the funds withheld (by check) to the Comptroller General (Claims Section).
(2)Returning of withheld funds to contractor. When funds withheld exceed the amount required to satisfy validated wage underpayments and assessed liquidated damages, return the funds to the contractor.
(3)Limitation on forwarding or returning funds. If the Department of Labor requested the withholding or if the findings are disputed (see 22.406-10(e)), the contracting officer must not forward the funds to the Comptroller General, or return them to the contractor without approval by the Department of Labor.
(4)Liquidated damages. Upon final administrative determination, the contracting officer must dispose of funds withheld or collected for liquidated damages in accordance with agency procedures.