(a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.
(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.
(2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its Alternate I.
(c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial items. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial items.
[48 FR 42159, Sept. 19, 1983, as amended at 50 FR 2270, Jan. 15, 1985; 50 FR 25680, June 20, 1985. Redesignated and amended at 60 FR 48241, 48249, Sept. 18, 1995; 72 FR 27385, May 15, 2007]
Title 48 published on 2014-10-01.
The following are only the Rules published in the Federal Register after the published date of Title 48.
For a complete list of all Rules, Proposed Rules, and Notices view the Rulemaking tab.
This is a list of United States Code sections, Statutes at Large, Public Laws, and Presidential Documents, which provide rulemaking authority for this CFR Part.