48 CFR 52.249-14 - Excusable Delays.

prev | next
52.249-14 Excusable Delays.

As prescribed in 49.505(b), insert the following clause in solicitations and contracts for supplies, services, construction, and research and development on a fee basis whenever a cost-reimbursement contract is contemplated. Also insert the clause in time-and-material contracts, and labor-hour contracts. When used in construction contracts, substitute the words “completion time” for “delivery schedule” in the last sentence of the clause.

Excusable Delays (APR 1984)

(a) Except for defaults of subcontractors at any tier, the Contractor shall not be in default because of any failure to perform this contract under its terms if the failure arises from causes beyond the control and without the fault or negligence of the Contractor. Examples of these causes are (1) acts of God or of the public enemy, (2) acts of the Government in either its sovereign or contractual capacity, (3) fires, (4) floods, (5) epidemics, (6) quarantine restrictions, (7) strikes, (8) freight embargoes, and (9) unusually severe weather. In each instance, the failure to perform must be beyond the control and without the fault or negligence of the Contractor. Default includes failure to make progress in the work so as to endanger performance.

(b) If the failure to perform is caused by the failure of a subcontractor at any tier to perform or make progress, and if the cause of the failure was beyond the control of both the Contractor and subcontractor, and without the fault or negligence of either, the Contractor shall not be deemed to be in default, unless -

(1) The subcontracted supplies or services were obtainable from other sources;

(2) The Contracting Officer ordered the Contractor in writing to purchase these supplies or services from the other source; and

(3) The Contractor failed to comply reasonably with this order.

(c) Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of the failure. If the Contracting Officer determines that any failure to perform results from one or more of the causes above, the delivery schedule shall be revised, subject to the rights of the Government under the termination clause of this contract.

(End of clause)
[ 48 FR 42478, Sept. 19, 1983, as amended at 72 FR 27394, May 15, 2007]

This is a list of United States Code sections, Statutes at Large, Public Laws, and Presidential Documents, which provide rulemaking authority for this CFR Part.

This list is taken from the Parallel Table of Authorities and Rules provided by GPO [Government Printing Office].

It is not guaranteed to be accurate or up-to-date, though we do refresh the database weekly. More limitations on accuracy are described at the GPO site.


United States Code
U.S. Code: Title 10 - ARMED FORCES

§ 2301 - Repealed. Pub. L. 103–355, title I, § 1501(a), Oct. 13, 1994, 108 Stat. 3296]

§ 2302 - Definitions

§ 2302a - Simplified acquisition threshold

§ 2302b - Implementation of simplified acquisition procedures

§ 2302c - Repealed. Pub. L. 114–328, div. A, title VIII, § 833(b)(5)(A)(i), Dec. 23, 2016, 130 Stat. 2285]

§ 2302d - Major system: definitional threshold amounts

§ 2303 - Applicability of chapter

§ 2303a - Repealed. Pub. L. 98–577, title III, § 302(c)(1), Oct. 30, 1984, 98 Stat. 3077]

§ 2304 - Contracts: competition requirements

§ 2304a - Task and delivery order contracts: general authority

§ 2304b - Task order contracts: advisory and assistance services

§ 2304c - Task and delivery order contracts: orders

§ 2304d - Task and delivery order contracts: definitions

§ 2304e - Contracts: prohibition on competition between Department of Defense and small businesses and certain other entities

§ 2305 - Contracts: planning, solicitation, evaluation, and award procedures

§ 2305a - Design-build selection procedures

§ 2306 - Kinds of contracts

§ 2306a - Cost or pricing data: truth in negotiations

§ 2306b - Multiyear contracts: acquisition of property

§ 2306c - Multiyear contracts: acquisition of services

§ 2307 - Contract financing

§ 2308 - Buy-to-budget acquisition: end items

§ 2309 - Allocation of appropriations

§ 2310 - Determinations and decisions

§ 2311 - Assignment and delegation of procurement functions and responsibilities

§ 2312 - Remission of liquidated damages

§ 2313 - Examination of records of contractor

§ 2313a - Defense Contract Audit Agency: annual report

§ 2314 - Laws inapplicable to agencies named in section 2303 of this title

§ 2315 - Law inapplicable to the procurement of automatic data processing equipment and services for certain defense purposes

§ 2316 - Disclosure of identity of contractor

§ 2317 - Repealed. Pub. L. 103–160, div. A, title VIII, § 821(a)(2), Nov. 30, 1993, 107 Stat. 1704]

§ 2318 - Advocates for competition

§ 2319 - Encouragement of new competitors

§ 2320 - Rights in technical data

§ 2321 - Validation of proprietary data restrictions

§ 2322 - Repealed. Pub. L. 102–484, div. A, title X, § 1052(25)(A), Oct. 23, 1992, 106 Stat. 2500]

§ 2323 - Contract goal for small disadvantaged businesses and certain institutions of higher education

§ 2323a - Credit for Indian contracting in meeting certain subcontracting goals for small disadvantaged businesses and certain institutions of higher education

§ 2324 - Allowable costs under defense contracts

§ 2325 - Restructuring costs

§ 2326 - Undefinitized contractual actions: restrictions

§ 2327 - Contracts: consideration of national security objectives

§ 2328 - Release of technical data under Freedom of Information Act: recovery of costs

§ 2329 - Repealed. Pub. L. 103–355, title I, § 1506(a), Oct. 13, 1994, 108 Stat. 3298]

§ 2330 - Procurement of contract services: management structure

§ 2330a - Procurement of services: tracking of purchases

§ 2331 - Procurement of services: contracts for professional and technical services

§ 2332 - Share-in-savings contracts

§ 2333 - Joint policies on requirements definition, contingency program management, and contingency contracting

§ 2334 - Independent cost estimation and cost analysis

§ 2335 - Prohibition on collection of political information

§ 2336 - Renumbered § 2679]

§ 2337 - Life-cycle management and product support

U.S. Code: Title 40 - PUBLIC BUILDINGS, PROPERTY, AND WORKS
U.S. Code: Title 51 - NATIONAL AND COMMERCIAL SPACE PROGRAMS

Title 48 published on 20-Nov-2017 05:26

The following are ALL rules, proposed rules, and notices (chronologically) published in the Federal Register relating to 48 CFR Part 52 after this date.

  • 2017-11-08; vol. 82 # 215 - Wednesday, November 8, 2017
    1. 82 FR 51774 - Federal Acquisition Regulation; Removal of Fair Pay and Safe Workplaces Rule Republication
      GPO FDSys XML | Text
      DEPARTMENT OF DEFENSE, GENERAL SERVICES ADMINISTRATION, NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
      Final rule.
        Effective date: November 6, 2017. Applicability dates: See section I.F of the Supplementary Information.
      48 CFR Parts 1, 4, 9, 17, 22, 42, and 52

Pages

The section you are viewing is cited by the following CFR sections.