Fla. Admin. Code Ann. R. 40E-7.672 - Compliance
The District shall monitor and evaluate Program performance and compliance as follows:
(1) Each District contract shall contain a provision requiring the Prime Contractor, during the
term of the contract, to comply with, as to tasks and proportionate dollar amounts throughout the term of the contract, all commitments made in their
bids or proposals for use of District SBEs.
(2) Each District contract shall contain a provision
requiring the Prime Contractor and any of its Subcontractor's maintenance of records, and information necessary to document compliance with the rules
herein and shall include the right of the District to inspect such records.
(3) Each District contract
shall contain a provision prohibiting any agreements between a Prime Contractor and an SBE in which the SBE promises not to provide subcontracting
quotations to other respondents or potential respondents.
(4) Prime Contractors must notify the District
when the need to add or replace an SBE Subcontractor arises and shall provide a completed Form No. 1373, "Small Business Enterprise Subcontractor
Revised Participation Schedule" (June 26, 2025) (https://flrules.org/Gateway/reference.asp?No=Ref-18103), which contains an
explanation of the addition or replacement of the SBE Ssubcontractor. Form No. 1373 is incorporated by reference herein and a copy can be obtained at
no cost by contacting the District's SBE Office, South Florida Water Management District, 3301 Gun Club Road, West Palm Beach, FL 33406,
(800)432-2045, ext. 6446, or (561)682-6446, or via email sbep@sfwmd.gov. In addition, a completed Form No. 0957, "Statement of Intent to Perform as a
Small Business Enterprise Subcontractor," incorporated by reference in subsection 40E-7.669(18), F.A.C., must be submitted if applicable.
(5) Failure of the Prime Contractor to meet its SBE requirements in a District contract will be a factor considered
by the District when making its responsibility determinations for future contract awards and when considering whether to place a Prime Contractor on
the Temporary or Permanent Suspension List under Rule 40E-7.218, F.A.C.
(6) Each District contract
awarded with an SBE goal shall contain a provision incorporating the rules herein by reference and a statement that failure to comply with the
requirements of the bid or proposal submitted by the Prime Contractor shall be considered a material breach of contract which may result in
suspension or debarment of the Businesses or individuals involved pursuant to Chapter 40E-7, F.A.C.
(7)
If a District SBE is in material breach of its contract with the District, as defined in subsection 40E-7.215(5), F.A.C., the District SBE shall be
decertified.
(8) If an SBE Subcontractor causes a Prime Contractor to be in material breach of its
contract with the District, as defined in subsection 40E-7.215(5), F.A.C., including, but not limited to, performance delay, the SBE Subcontractor
shall be decertified.
Notes
Rulemaking Authority 373.044, 373.113 FS. Law Implemented 373.1135 FS.
New 8-3-06, Amended 8-29-13, 12-9-20.
State regulations are updated quarterly; we currently have two versions available. Below is a comparison between our most recent version and the prior quarterly release. More comparison features will be added as we have more versions to compare.
The
(1) Each District contract shall contain a provision requiring the contractor , during the term of the contract, to comply with, as to tasks and proportionate dollar amounts throughout the term of the contract, all commitments made in their bids or proposals for use of SBEs.
(2) Each District contract shall contain a provision requiring maintenance of records, and information necessary to document compliance with the rules under this Part and shall include the right of the District to inspect such records.
(3) Each District contract shall contain a provision prohibiting any agreements between a contractor and a SBE in which the SBE promises not to provide subcontracting quotations to other respondents or potential respondents.
(4) Prime Contractors must notify the District when the need to add or replace an SBE subcontractor arises and shall provide a completed Form No. 1373, "Small Business Enterprise Subcontractor Revised Participation Schedule" effective (August 29, 2013) (http://www.flrules.org/Gateway/reference.asp?No=Ref-03067), which contains an explanation of the addition or replacement of the SBE subcontractor . Form 1373 is incorporated by reference herein and a copy can be obtained at no cost by contacting the South Florida Water Management District Clerk's Office, South Florida Water Management District , 3301 Gun Club Road, West Palm Beach, FL 33406, (800)432-2045, ext. 6805, or (561)682-6805. In addition, a completed Form No. 0957, "Statement of Intent to Perform as a Small Business Enterprise Subcontractor, " incorporated by reference in paragraph 40E-7.670(2)(a), F.A.C., must be submitted if applicable.
(5) Failure of the Prime Contractor to meet its SBE requirements in a District contract will be a factor considered by the District when the District makes its responsibility determinations for future District contract awards and when the District considers whether to place a contractor on the Temporary or Permanent Suspension List under Rule 40E-7.218, F.A.C.
(6) Each District contract awarded with SBE participation shall contain a provision incorporating the rules under this part by reference and a statement that failure to comply with the requirements of the bid or proposal submitted to the District by a contractor shall be considered a material breach of contract which may result in suspension or debarment of the firms or individuals involved pursuant to Chapter 40E-7, F.A.C.
(7) If an SBE Prime contractor is in material breach of its contract with the District , as defined in subsection 40E-7.215(5), F.A.C., the SBE Prime contractor shall be decertified.
(8) If an SBE subcontractor causes Prime Contractor to be in material breach of its contract with the District , as defined in subsection 40E-7.215(5), F.A.C., including, but not limited to, performance delay, the SBE subcontractor shall be decertified.
Notes
Rulemaking Authority 373.044, 373.113 FS. Law Implemented 373.1135 FS.
New 8-3-06, Amended 8-29-13, 12-9-20.